Cases Decided in the United States Court of Claims ... with Report of Decisions of the Supreme Court in Court of Claims Cases, Volumul 116The Court, 1950 |
Din interiorul cărții
Rezultatele 1 - 5 din 100
Pagina 3
... excavation prevented the excavation to the indicated slope lines and in order to accomplish building of the dam as planned , new slope lines were established which required considerable additional excavation , all such excavation was ...
... excavation prevented the excavation to the indicated slope lines and in order to accomplish building of the dam as planned , new slope lines were established which required considerable additional excavation , all such excavation was ...
Pagina 10
... excavation and some rock excavation had been done within this cofferdam . There had also been some rock excavation in the east abutment area . At the time of the change order ( June 5 , 1935 ) referred to in Finding No. 11 , plaintiffs ...
... excavation and some rock excavation had been done within this cofferdam . There had also been some rock excavation in the east abutment area . At the time of the change order ( June 5 , 1935 ) referred to in Finding No. 11 , plaintiffs ...
Pagina 29
... excavation of a greater volume of the other deposits than the volume of glacial till used by plaintiffs . The expense to plaintiffs in excavating and proc- essing the aggregates required if the glacial till had been stripped and wasted ...
... excavation of a greater volume of the other deposits than the volume of glacial till used by plaintiffs . The expense to plaintiffs in excavating and proc- essing the aggregates required if the glacial till had been stripped and wasted ...
Pagina 30
... excavating and processing 1,454,940 cubic yards less of aggregates from the Brett deposits than were actually ... excavation and removal of the required materials in a manner satisfactory to the contracting officer and so as to ...
... excavating and processing 1,454,940 cubic yards less of aggregates from the Brett deposits than were actually ... excavation and removal of the required materials in a manner satisfactory to the contracting officer and so as to ...
Pagina 37
... excavate and process sand and gravel from the Brett deposits cost plaintiffs $ 0.156029 per cubic yard . If 39 ... excavation for the foundations of the dam three rather steep and deep gorges were encountered , known in the record ...
... excavate and process sand and gravel from the Brett deposits cost plaintiffs $ 0.156029 per cubic yard . If 39 ... excavation for the foundations of the dam three rather steep and deep gorges were encountered , known in the record ...
Alte ediții - Afișează-le pe toate
Cases Decided in the Court of Claims of the United States, Volumul 64 United States. Court of Claims Vizualizare completă - 1928 |
Cases Decided in the Court of Claims of the United States, Volumul 92 United States. Court of Claims Vizualizare completă - 1941 |
Termeni și expresii frecvente
acres additional adjustment Alaska Railroad alleged amount April authorized cause of action change order charter cofferdam Company compensation completion concrete construction contracting officer contraction joints contractor Corporation cost Court of Claims cubic yard damages dead-weight December December 21 decision defendant defendant's delay determined drawings employees engineer entitled to recover equipment evidence fact feet filed findings follows fumigant furnished gates glacial till Government Grand Coulee Dam grout holes installed January January 21 Judge judgment July June June 12 labor land letter March material ment November November 15 October operation Opinion Order for Changes paid paragraph parties patent payment percent period petition placed plaintiff powerhouse prior purchase railroad removal rental Reporter's Statement reservation retired rock excavation schedule Section slope specifications Stat statute tiffs tion tract Umpqua unit prices vessel War Shipping Administration
Pasaje populare
Pagina 360 - Contractor, including, but not restricted to, acts of God, or of the public enemy, acts of the Government...
Pagina 397 - No person who holds an office the salary or annual compensation attached to which amounts to the sum of two thousand five hundred dollars shall be appointed to or hold any other office to which compensation is attached unless specially heretofore or hereafter specially authorized thereto by law...
Pagina 359 - Officer in writing of: (1) subsurface or latent physical conditions at the site differing materially from those indicated in this contract, or (2) unknown physical conditions at the site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inhering in work of the character provided for in this contract.
Pagina xx - To confer jurisdiction upon the Court of Claims to hear, determine, and render judgment upon the claim of Herbert M.
Pagina 514 - Is permitted only upon the condition that every such laborer and mechanic shall be compensated for all hours worked In excess of eight hours per day at not less than one and one-half times the basic rate of pay.
Pagina 575 - The Emergency Court of Appeals, and the Supreme Court upon review of judgments and orders of the Emergency Court of Appeals, shall have exclusive jurisdiction to determine the validity of any regulation or order issued under section 2...
Pagina 295 - ... remission or mitigation of such fine, penalty, or forfeiture, the Secretary of the Treasury, or the Secretary of Commerce, if he finds that such fine, penalty, or forfeiture was incurred without willful negligence or without any intention on the part of the petitioner to defraud the revenue or to violate the law...
Pagina 221 - If the Contractor refuses or fails to prosecute the work, or any separable part thereof, with such diligence as will insure its completion within the time specified in this contract, or any extension thereof, or fails to complete said work within such time, the Government may, by written notice to the Contractor, terminate his right to proceed with the work or such part of the work as to which there has been delay.
Pagina 671 - No interest shall be allowed on any claim up to the time of the rendition of judgment by the Court of Claims, unless upon a contract expressly stipulating for the payment of interest...
Pagina 746 - In the event It Is found by the contracting officer that any laborer or mechanic employed by the contractor or any subcontractor directly on the site of the work covered by the contract has been or is being paid a rate of wages less than the rate of wages required by the contract to be paid...